H. E. Crook Co., Inc. v. United States
270 U.S. 4 (1926)

Annotate this Case

U.S. Supreme Court

H. E. Crook Co., Inc. v. United States, 270 U.S. 4 (1926)

H. E. Crook Company, Inc. v. United States

No. 122

Argued January 12, 1926

Decided January 25, 1926

270 U.S. 4

Syllabus

Where a contract for furnishing and installing heating plants in buildings to be erected for the government by other contractors showed on its face that progress under it would be dependent on the progress of the buildings, and, though strictly limiting the time for the contractor's performance, made no reference to delays by the government save as grounds for time extensions to the contractor, and the contractor therein agreed to accept the contract price in full satisfaction for all work done under the contract, reduced by damages deducted for its delays and increased or reduced by the price of any changes ordered by the government, and stipulated that the contract price should cover all expenses of any

Page 270 U. S. 5

nature connected with the work to be done, held, that the Government was not bound to make good losses suffered by the contractor in performing the contract due to delays in completing the buildings.

59 Ct. Cls. 593 affirmed.

Appeal from a judgment of the Court of Claims denying a claim for damages due to delay in enabling the claimant to perform its contract.

Official Supreme Court case law is only found in the print version of the United States Reports. Justia case law is provided for general informational purposes only, and may not reflect current legal developments, verdicts or settlements. We make no warranties or guarantees about the accuracy, completeness, or adequacy of the information contained on this site or information linked to from this site. Please check official sources.